我们签订合同的主要目的是保证自己的利益,任何合作在开始前,肯定是要签署好相关合同的,二十范文网小编今天就为您带来了2023年设计合同模板5篇,相信一定会对你有所帮助。
2023年设计合同模板篇1
发包人(甲方): 设计人(乙方):
根据《中华人民共和国合同法》、《建设工程勘察设计合同条例》和建筑装饰工程等行业规范及有关法律、法规的规定,甲、乙双方本着平等、自愿、公平、诚实信用的原则,经友好协商,现甲方委托乙方对装饰工程进行方案设计、深化方案设计与施工图纸设计及配套服务工作。签订本合同,以资信守。 第一条 工程概况
1、工程名称: 2、工程地点:
第二条 设计范围及内容
1、按甲方确认的交楼标准方案做、······个户型样板房的图纸设计。 2、按甲方确认的交楼标准方案做标准层n个户型的图纸深化设计。即、。 3、座首层住宅大堂、座首层电梯厅、座标准层电梯厅装修方案的图纸深化设计。 4、主要装修材料品牌、参考价格、样品展板(考虑选用材料的耐用性、环保及节能) 5、对样板房及售楼大厅的家具饰物选择和摆设提出建议方案,及时到现场做工作指导。 具体详见附件清单
第三条 设计服务要求
1、设计标准及目标要求
本项目定位为 风格。 2、图纸设计阶段要求
(1) 概念设计阶段:根据甲方提供的设计要求任务书及现场实地查看进行概念性设计。 (2) 方案设计阶段:根据双方对设计讨论的修改意见进行深化方案设计,并达到制作
(3) 施工图设计阶段:根据甲方确认的深化设计方案,进行施工图细节设计。 3、装饰施工造价及购置成本控制如下表
4、设计配合服务工作
(1) 提供优化意见书或修改图纸
(2) 项目开始施工前,乙方负责向甲方及施工单位进行设计交底,解答甲方及施工队提
(3) 根据现场的实际情况对施工图纸进行必要的修改与完善。
(4) 根据工程进展情况及甲方的工程安排,乙方应每两周视察工地一次(总次数不得少
(5) 根据设计选料要求,配合甲方对施工单位选购的主要材料进行选择和确认,并参与
第四条 甲方向乙方提交的有关资料及文件:
第五条 乙方向甲方交付的设计文件
第六条 设计服务费及支付方式
本合同项目的设计费为总包干价¥ 元人民币。设计费支付进度详见下表
注:可按清单所列的完成项目按以上比例计算支付金额。
第七条 验收标准
1、图纸设计标准应满足国家与地方有关建筑装饰工程设计之法律、法规、规章和条例的规定; 2、软装选购效果应达到图片及设计说明要求;
3、乙方设计硬、软装造价成本应控制在原确认造价的正负5%内,超过5%以上由乙方支付。
甲方应将工程各项主材的实样和价格,交由乙方确认,再行采购或发包,以控制造价。 第八条 家具及饰品的选样与采购
第九条 双方权利及义务:
一、甲方权利及义务:
1、甲方按本合同第四条及第五条规定的内容,在规定的时间内向乙方提交资料及文件,并对其完整性、正确性负责。甲方提交上述资料及文件超过规定期限15天以内的,乙方有权按本合同规定顺延交付设计文件的时间;超过规定期限15天以上时,乙方有权要求双方重新确定提交设计文件的时间。
2、甲方变更委托设计项目、规模、条件或因提交的资料错误,或所提交资料作较大修改,要求乙方作较大返工时,乙方在接通知后3天内向甲方提交返工费用预算(含工作量及计算依据),经双方共同协商后签订补充协议。
3、因乙方提交设计资料的设计深度、设计风格、设计质量等不符合甲方原来的要求甲方有权终止合同,若甲方再要求乙方返工的,甲方不再另行支付设计费用。
4、在合同履行期间,甲方违反本合同约定无理解除合同,乙方未开始设计工作的,不退还甲方支付的定金;已开始设计工作的,甲方应根据乙方已经进行的实际工作量予以补偿。
5、甲方派代表协调甲乙双方及其他设计方的工作,签收乙方提交的文件,在三个工作日内答复乙方。若三个工作日内不作答复,则视同认可。对其中应由甲方解决的问题及时组织协调甲方有关部门及人员予以落实,否则顺延提交设计文件的时间。
二、 乙方权利及义务:
1、乙方应按本合同第五条规定的内容、时间及份数向甲方交付设计资料及文件。 2、为保证设计质量和效果,乙方应保证由设计总监 主持设计和定案。 3、在施工前进行技术交底,处理有关设计问题,负责设计变更,参加竣工验收。委派专业负责人在现场确认施工方提交的材料样板、施工样板、解决各专业技术问题,进行隐蔽工程验收等,并委派专业负责人协同甲方进行相关材料﹙含软装部分即家具及饰品﹚的采购。
4、乙方应按国家规定和合同约定的技术规范、标准规程及甲方提出的设计要求进行工程设计,严格做好设计质量和效果保障措施,确保按合同规定的进度要求向甲方提交质量合格的设计资料,对设计文件出现的遗漏或错误负责修改或补充,造成甲方损失由乙方承担,工期不予顺延。
5、合同生效后,乙方必须应甲方的要求提供上述约定内容及次数的现场服务,乙方应解决施工中有关设计问题,确认施工方材料样板、施工样板,负责设计变更,软装设计、订购、采购、摆放,竣工验收,服务费用包含在设计费内。
6、合同生效后,乙方要求终止或解除合同,乙方除返还甲方已付款项外,还应双倍返还定金。
7、乙方交付设计资料及文件后,按规定参加甲方有关上级设计审查及根据审查结论负责不超出原定计划任务书范围内的必要调整补充。
8、乙方项目负责人或专业负责人现场施工服务应双方协定时间并至少往返及费用自理。项目负责人或专业负责人每缺席一次,应承担 元/次违约金,累计缺席三次以上时,甲方有权解除合同并按照甲方已经确认的图纸工作量办理结算,同时,乙方应按设计费总额的 10 %向甲方支付违约金。
9、乙方应对园林设计单位提供的样板房入室花园、阳台花园及大露台的绿化景观设计进行审核及修正,使之与样板房装修风格相匹配和协调统一。
10、乙方应向甲方提供公司(包括境外公司)业绩及设计精英等资料,配合甲方做好本项目楼盘营销策划宣传工作,共营双赢局面。
11、乙方在方案设计、施工图设计的各阶段设计中应提供投资估算、施工图概算报甲方审批。
第十条 违约责任
一、甲方不能按本合同约定向乙方支付设计费的,每逾期一天应承担未付金额2‰的违约金。
二、乙方对设计资料及文件出现的遗漏或错误负责修改、补充。由于乙方设计错误造成工程质量问题或其他损失,乙方除负责采取补救措施外,应免收受损部分的设计费,并负责赔偿由此给甲方造成的实际损失。赔偿金额双方商定,赔偿总额不超过设计费总额。
三、由于乙方自身原因延误了按本合同规定的设计文件交付时间,每延误一天,应承担该项目阶段应收设计费2‰的违约金。逾期超过三十天,甲方有权解除合同,乙方除支付前述违约金外,甲方已付款项乙方须全部返还,乙方还须赔偿由此给甲方造成的损失,赔偿总额不超过设计费总额。
四、乙方不能按照甲方的要求(质量、时间)提交设计文件或乙方不能胜任本设计任务时,甲方有权单方解除合同,并按照甲方已经确认的图纸工作量办理结算。
第十一条 文件的版权/著作权
乙方应保证其提交的设计成果不侵犯第三人的著作权或其它合法权利,否则应由乙方承担责任,并赔偿甲方损失。
第十二条 转让条款
未经合同其他方书面同意,任何一方不得全部或部分转让其在本合同项下的权利和义务。
第十三条 合同终止和解除
一、合同解除,
1、在本合同签订后、乙方提交前期方案设计成果前:如甲方单方解除本合同,则甲方应根据乙方已经进行的设计工作,向乙方支付相应的设计费,同时须额外补偿乙方人民币 元;如乙方单方解除本合同,则应退还已经收取的设计费并额外补偿甲方人民币 元。
2、在本合同签订后、乙方提交优化方案设计成果前:如甲方单方解除本合同,则甲方应根据乙方已经进行的设计工作,向乙方支付相应的设计费,同时须额外补偿乙方人民币 元;如乙方单方解除本合同,则应退还已经收取的设计费并额外补偿甲方人民币 元。
3、在本合同签订后、乙方提交施工图纸设计成果前:如甲方单方解除本合同,则甲方应根据乙方已经进行的设计工作,向乙方支付相应的设计费,同时须额外补偿乙方人民币 元;如乙方单方解除本合同,则应退还已经收取的设计费并额外补偿甲方人民币 元。
4、乙方提交施工图纸成果并被甲方接受后,任何一方均不得单方解除本合同。
二、有下列情形之一的, 合同权利义务终止 1、本合同已按约定履行完毕;
2、本合同经各方协商一致而终止;
3、因乙方提交设计资料的设计深度、设计风格、设计质量等不符合甲方原来的要求甲方有权终止合同,若甲方再要求乙方返工的,甲方不再另行支付设计费用。
4、本合同因其中一方出现本条第(一)款的违约情况(包括一方擅自转让本合同项下权利义务行为),另一方发出解除合同的通知;
5、法律法规规定终止的其他情形。
第十四条 保密条款
一、在本合同订立前、履行中、终止后未经合同其他方书面同意,任何一方对本合同和各方相互提供的资料、信息(包括但不限于商业秘密、技术资料、图纸、数据、以及与业务有关的客户的信息及其他信息等)负保密责任。
二、甲方可在宣传本项目时使用乙方的设计成果。
三、任何一方违反上述约定,责任方应按合同总设计费的10%向合同其他方支付违约金,违约金不足以赔偿合同他方损失的,应按合同其他方的实际损失赔偿。
四、本保密条款具有独立性,不受本合同的终止或解除的影响。
第十五条 免责条款
由于不能预见、不能避免和不能克服的自然原因或社会原因,致使本合同不能履行或者不能完全履行时,遇到上述不可抗力事件的一方,应立即书面通知合同其他方,并应在不可抗力事件发生后十五天内,向合同其他方提供经不可抗力事件发生地区公证机构出具的证明合同不能履行或需要延期履行、部分履行的有效证明文件,由合同各方按事件对履行合同影响的程度协商决定是否解除合同、或者部分或全部免除履行合同的责任、或者延期履行合同。遭受不可抗力的一方未履行上述义务的,不能免除其违约责任。
第十六条 法律适用
对本合同的订立、履行、解释、效力和争议的解决均适用中华人民共和国法律。
第十七条 争议的解决
因本合同的签订、履行而发生争议的,合同各方应本着友好、协作的态度进行协商;协商不成的,双方同意由本项目所在地的中级人民法院进行裁决。
第十八条 合同附件
本合同连同下列附件组成合同文件 附件一、设计费用清单(共1页)当上述附件的内容与本合同之条款不一致时,以本合同之条款为依据。
第十九条 其它
1、本合同未尽事宜,经双方友好协商,另签补充协议。补充协议与本合同具有同等法律效力。
2、本合同一式贰份,甲乙双方各执一份,均具同等法律效力。
甲方: 乙方: 地址: 地址: 法定代表人: (或授权签约人): 签约人:
日期: 年 月 日 日期: 年 月 日
2023年设计合同模板篇2
甲方:_______________
乙方:_______________
双方本着诚信为本,互惠互利,公平交易的原则,就甲方委托乙方设计服务事宜达成如下协议:
一、服务内容
项目:_____________________;
内容、规格、要求:_________;
费用:_____________________;
备注:_____________________;
合同总费用:为人民币_________元整(_________元),由甲方付给乙方。依照企业或产品品牌¥_________元,_________提供版权转移_________电子文件。
二、甲乙双方责任
甲方需提供明确的工作要求,同时及时向乙方提供相关的资料及咨询等;甲方需及时对乙方提出的设计方案进行反馈;甲方须按合同规定向乙方支付有关费用。
乙方需通过电子文件向甲方提供详细设计方案,供甲方指定人员审定;乙方需严格按甲方要求,以专业水准进行合同规定之工作;乙方需遵守甲方商业(资料)机密。
乙方需向甲方提供至少五款的不同设计方案,供甲方确认,并在双方沟通基础上进行修改至完善;若因乙方水准或设计思路偏差所致,乙方提交设计稿无法为甲方所认可,乙方需再次向甲方提供设计方案。当前三次向甲方所提供的设计方案,在经乙方与甲方决策人积极沟通都不被甲方认可的情况下,甲方有权要求终止合同。甲,乙双方诚信为本,协作完成上述工作内容时间要求为:______年_____月_____日前。
三、付款方式
自甲乙双方签订合同之日,甲方向乙方预付合同总金额的50%作为订金。
本合同完成之时,甲方向乙方一次性付清合同余款计_________元。
四、其它事项
甲乙双方均不得无故终止协议,否则违约方需承担对方的经济损失。
甲方向乙方付清合同全款后,乙方向甲方提供作品的电子文件和版权转移。甲方采用乙方作品的前提条件是甲方已向乙方付清该作品全部费用,或经乙方同意。
本合同未尽事宜,由甲乙双方另行协商解决。合同书自签订之日起即告生效。
本合同传真件有效,一式_________份,双方各执_________份,具有同等法律效力。
甲方(盖章):_______________
法定代表人(签字):_________
_________年________月______日
签订地点:___________________
乙方(盖章):_______________
法定代表人(签字):_________
_________年________月______日
签订地点:__________________
2023年设计合同模板篇3
工程名称:___________
工程地点:___________
合同编号:___________
设计证书等级:_________
签订日期:___________
发包人:________________________
设计人:________________________
发包人委托设计人承担_________工程设计,经双方协商一致,签订本合同。
第一条 本合同依据下列文件签订:
1.1 《中华人民共和国合同法》、《中华人民共和国建筑法》、《建设工程勘察设计市场管理规定》。
1.2 国家及地方有关建设工程勘察设计管理法规和规章。
1.3 建设工程批准文件。
第二条 本合同设计项目的内容:
名称:________________________; 规模:__________________________;
阶段:________________________; 投资:__________________________;
设计费 :______________________; 序号:__________________________;
分项目名称:__________________; 建设规模:______________________;
设计阶段及内容:______________; 估算总投资:____________________;
费率%:______________________; 估算设计费:____________________;
层数:________________________; 建筑面积:______________________;
方案初步设计:________________; 施工图(万元):_________________;
第三条 发包人应向设计人提交的有关资料及文件:
序号:________________________; 资料及文件名称:________________;
份数:________________________; 提交日期:______________________;
有关事宜:____________________;
第四条 设计人应向发包人音乐会的设计资料及文件:
序号:________________________; 资料及文件名称:________________;
份数:________________________; 提交日期:______________________;
有关事宜:____________________;
第五条 本合同设计收费估算为 ___元人民币。设计费支付进度详见下表。
付费次序 占总设计费% 付费额(元) 付费时间(由交付设计文件所决定)
第一次付费 20%定金 ___________ 本合同签订后三日内
第二次付费 ___________ ___________ __________________
第三次付费 ___________ ___________ __________________
第四次付费 ___________ ___________ __________________
第五次付费 ___________ ___________ __________________
说明:
1. 提交各阶段设计文件的同时支付各阶段设计费。
2. 在提交最后一部分施工图的同时结清全部设计费,不留尾款。
3.实际设计费按初步设计概算(施工图设计概算)核定,多退少补。实际设计费与估算设计费出现差额时,双方另行签订补充协议。
4. 本合同履行后,定金抵作设计费。
第六条 双方责任
6.1 发包人责任:
6.1.1发包人按本合同第三条规定的内容,在规定的时间内向设计人提交资料及文件,并对其完整性、正确性及时限负责,发包人不得要求设计人违反国家有关标准进行设计。
发包人提交上述资料及文件超过规定期限15天以内,设计人按合同第四条规定交付设计文件时间顺延;超过规定期限15天以上时,设计人员有权重新确定提交设计文件的时间。
6.1.2发包人变更委托设计项目、规模、条件或因提交的资料错误,或所提交资料作全套修改,以致造成设计人设计需返工时,双方除需另行协商签订补充协议(或另订合同)、重新明确有关条款外,发包人应按设计人所耗工作量向设计人增付设计费。
在未签合同前发包人已同意,设计人为发包人所做的各项设计工作,应按收费标准,相应支付设计费。
6.1.3 发包人要求设计人比合同规定时间提前交付设计资料及文件时,如果设计人能够做到,发包人应根据设计人提前投入的工作量,向设计人支付赶工费。
6.1.4 发包人应为派赴现场处理有关设计问题的工作人员提供必要的工作生活及交通等方便条件。
6.1.5发包人应保护设计人的投标书、设计方案、文件、资料图纸、数据、计算软件和专利技术。未经设计人同意,发包人对设计人交付的设计资料及文件不得擅自修改、复制或向第三人转让或用于本合同外的项目,如发生以上情况,发包人应负法律责任,设计人有权向发包人提出索赔。
6.2 设计人责任:
6.2.1 设计人应按国家技术规范、标准、规程及发包人提出的设计要求,进行工程设计,按合同规定的进度要求提交质量合格的设计资料,并对其负责。
6.2.2 设计人采用的主要技术标准是:
6.2.3 设计合理使用年限为 ______年。
6.2.4 设计人按本合同第二条和第四条规定的内容、进度及份数向发包人交付资料及文件。
6.2.5设计人交付设计资料及文件后,按规定参加有关的设计审查,并根据审查结论负责对不超出原定范围的内容做必要调整补充。设计人按合同规定时限交付设计资料及文件,本年内项目开始施工,负责向发包人及施工单位进行设计交底、处理有关设计问题和参加竣工验收。在一年内项目尚未开始施工,设计人仍负责上述工作,但应按所需工作量向发包人适当收取咨询服务费,收费额由双方商定。
6.2.6设计人应保护发包人的知识产权,不得向第三人泄露、转让发包人提交的产品图纸等技术经济资料。如发生以上情况并给发包人造成经济损失,发包人有权向设计人索赔。
第七条 违约责任:
7.1在合同履行期间,发包人要求终止或解除合同,设计人未开始设计工作的,不退还发包人已付的定金;已开始设计工作的,发包人应根据设计人已进行的实际工作量,不足一半时,按该阶段设计费的一半支付;超过一半时,按该阶段设计费的全部支付。
7.2 发包人应按本合同第五条规定的金额和时间向设计人支付设计费,每逾期支付一天,应承担支付金额%的逾期违约金。逾期超过30天以上时,设计人有权暂停履行下阶段工作,并书面通知发包人。发包人的上级或设计审批部门对设计文件不审批或本合同项目停缓建,发包人均按7.1条规定支付设计费。
7.3设计人对设计资料及文件出现的遗漏或错误负责修改或补充。由于设计人员错误造成工程质量事故损失,设计人除负责采取补救措施外,应免收直接受损失部分的设计费。损失严重的根据损失的程度和设计人责任大小向发包人支付赔偿金,赔偿金由双方商定为实际损失的___%。
7.4 由于设计人自身原因,延误了按本合同第四条规定的设计资料及设计文件的交付时间,每延误一天,应减收该项目应收设计费的 。
7.5 合同生效后,设计人要求终止或解除合同,设计人应双倍返还定金。
第八条 其他
8.1 发包人要求设计人派专人留驻施工现场进行配合与解决有关问题时,双方应另行签订补充协议或技术咨询服务合同。
8.2设计人为本合同项目所采用的国家或地方标准图,由发包人自费向有关出版部门购买。本合同第四条规定设计人交付的设计资料及文件份数超过《工程设计收费标准》规定的份数,设计人另收工本费。
8.3本工程设计资料及文件中,建筑材料、建筑构配件和设备,应当注明其规格、型号、性能等技术指标,设计人不得指定生产厂、供应商。发包人需要设计人的设计人员配合加工定货时,所需要费用由发包人承担。
8.4发包人委托设计配合引进项目的设计任务,从询价、对外谈判、国内外技术考察直至建成投产的各个阶段,应吸收承担有关设计任务的设计人参加。出国费用,除制装费外,其他费用由发包支付。
8.5 发包人委托设计人承担本合同内容之外的工作服务,另行支付费用。
8.6 由于不可抗力因素致使合同无法履行时,双方应及时协商解决。
8.7凡因本合同或与本合同有关的一切争议,双方应及时协商解决;协商不成时,双方同意由中国国际经济贸易仲裁委员会天津国际经济金融仲裁中心进行仲裁。仲裁裁决是终局的,对双方均有约束力。
8.8 本合同一式 ____份,发包人 _____份,设计人 ______份。
8.9 本合同经双方签章并在发包人向设计人支付订金后生效。
8.10 本合同生效后,按规定到相关主管部门规定的审查部门备案。双方履行完合同规定的义务后,本合同即行终止。
8.11本合同未尽事宜,双方可签订补充协议,有关协议及双方认可的来往传真、电子邮件、会议纪要等,均为本合同组成部分,与本合同具有同等法律效力。
8.12 其他约定事项:
发包人名称(盖章):_____________________ 设计人名称(盖章):_______________
法定代表人(签字):_____________________ 法定代表人(签字):_______________
委托代理人(签字):_____________________ 委托代理人(签字):_______________
住 所:__________ 邮政编码:_______ 住 所:_________ 邮政编码:________
电 话:__________ 传 真:_________ 电 话:_________ 传 真:__________
开户银行:________ 银行帐号:_______ 开户银行:________ 银行帐号:________
2023年设计合同模板篇4
委托方: (以下简称甲方)
受托方: (以下简称乙方)
甲方因装修工程的需要,委托乙方进行室内装修设计工作,经双方协商一致,签订本合同。
一、 设计工程概况
1.设计工程名称:
2.设计工程地点:
3.设计工程面积约: ㎡
4.设计工程范围:
二、 设计时间
1.设计期限:
设计期限为 天,从乙方收到甲方支付的定金后开始计算,到向甲方交付全套设计图纸之日为止。因甲方变更设计要求或对乙方意见未及时答复,其耽误的时间应从合同约定的设计期限中相应扣除。
2.设计交图步骤及时间:
(1)甲、乙双方当面协商满意后确定设计详细内容及金额,即签定本合同,同时支付定金人民币 元。乙方收到定金后 天内,向甲方提交装修设计方案图及平面功能定位图,如乙方未提交装修设计方案图及平面功能定位图,则双倍向甲方返还定金。
(2)甲、乙双方初步确定平面方案及初步确定设计概念后,同时支付首期设计费人民币 (按以上2(1)支付的人民币定金自动转为首期设计费)。乙方收到设计费后 天内,向甲方提交较详细装修设计方案包括主要立面图。
(3)甲方确认立面方案、天花方案即支付第二期设计费人民币,乙方收到设计费案后 天内,向甲方提交详细装修施工图及效果图。
(4)甲方签字确认设计施工图后即支付第三期设计费人民币,乙方向甲方提供全套正式设计施工图纸。
(5)工地开工后设计师配合施工队现场指导并对业主提供材料及工程质量咨询服务。
三、 提交成果
序号
图纸名称
份数
内容要求
提交时间
1 装修设计方案图 1套平面、天花、主要立面 年 月 日前
2装修施工图 1套平面、天花、立面、剖面、大样、 年 月 日前备注
1、《装修施工图》为pdf文件且应达到施工队依图施工之深度;
四、 双方责任
1.甲方应按合同规定及时支付设计费。
2.甲方应将设计要求准确、简明扼要的告之乙方设计人员,并不得随意变更(除了合理的变更)。甲方变更设计委托事项或因提交的资料错误,或对所提供资料作较大修改,造成乙方设计返工,除双方需协商签订补充合同(或另订合同),重新明确有关条款外,甲方应按乙方所耗工作量向乙方支付相应的费用。
3.甲方应到乙方公司所在地提出设计要求、签定合同、看图定样、支付设计费。
4.乙方须按合同规定的时间提交设计图纸。
5.乙方应本着认真负责的精神,按照甲方的要求完成设计。
7.若甲方未能按时支付设计费,乙方有权拒绝甲方提出的下一步工作要求。
8、乙方履行了本合同所规定的义务后,甲方向乙方支付剩余设计费人民币 元。
9、乙方未履行本合同规定的任何一项义务视为根本违约,甲方有权解除本合同,乙方并赔偿甲方因此造成的损失。
五、 设计费金额、支付时间与方式
1.设计费总额:人民币¥ 元,( ),即 元/㎡。
2.支付时间:
(1)双方签订委托设计合同时,甲方即应向乙方支付定金,即人民币¥ 元。(-);
(2)甲方支付第一期的设计费即人民币¥ 元。(-);
(3)甲方支付第二期的设计费即人民币¥ 元。(-);
(4)甲方支付第三期的设计费即人民币¥ 元。(-);
(5)若有双方协商同意增加的设计费应在工程开工前支付给乙方;乙方应甲方要求,超出合同规定为甲方提供服务所增加的费用,在工程峻工前由甲方支付给乙方。
3.支付方式
甲,乙双方共同协商支付方式。
六. 违约责任和争议的解决
1.甲方在乙方提供有关设计图纸后,未在合同规定的期限内支付设计费,或乙方无特殊情况延迟交付图纸,均应视为违反合同约定。按每日100元予以处罚。
2.合同生效后,甲、乙方无故要求终止或解除合同时,应以双倍定金赔偿无过错方(不可抗力除外)。
3.甲、乙双方在履行合同过程中,如有争议,应友好协商解决。协商不成任何一方可向合同签订地法院提出诉讼。
七、 合同效力
本合同壹式肆份,甲乙双方各执贰份。合同经双方签字后生效。本合同设计工程峻工后终止 。
甲方(签字盖章):电话:
乙方(签字盖章): 电话:
合同签订时间: 年月 日
2023年设计合同模板篇5
design contract for construction project (ii)
(专业建设工程设计合同)
(design contract for professional construction project)
工 程 名 称: 10kv变电所新建工程
project name:10kv substation new construction
工 程 地 点:
project site:
合 同 编号:contract no.:
(由设计人编填) (filled in by designer)
设计证书等级: 设证甲级a121001826
design certification rank: design certificate class a 121001826
发 包 人:employer:
设 计 人: 电力勘察设计院
designer: electric power survey design institute
签 订 日 期:date:
中华人民共和国建设部国家工商行政管理??
supervised and manufactured byministry of construction of peoplesquo;s republic of
china and the state administration of industry and commerce
发包人:employer:
设计人:电力勘察设计院 designer: electric power survey design institute
发包人委托设计人承担 10kv变电所新建工程设计,工程地点为 ,经双方协商一致,签订本合同,共同执行。
the employer entrusts the designer to undertake 10kv star mall plaza 1 # substation new construction; the project site is no.6, beisquo;er zhong road, tiexi district, shenyang city. upon agreement by both parties through consultation, the two parties shall sign and implement the contract jointly.
第一条 本合同签订依据 article 1: this contract is signed in accordance with:
1.1《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》。
1.1 contract law of the peoplesquo;s republic of china, construction law of the people's republic of china and market regulations of construction survey and design.
1.2国家及地方有关建设工程勘察设计管理法规和规章。
1.2 laws and regulations of the related state and local construction survey and design management.
1.3建设工程批准文件。1.3 documents of approval for construction.
第二条设计依据article 2 design basis
2.1发包人给设计人的委托书或设计中标文件
2.1 the trust deed or design documents of the tender accepted provided to the designer by the employer;
2.2发包人提交的基础资料2.2 fundamental materials submitted by the employer;
2.3设计人采用的主要技术标准是:2.3 the major technical standards adopted by the designer are:
b-01r5-sj-02-20xx标准、规程、规范
b-01r5-sj-02-20xx standards, procedures, norms
第三条合同文件的优先次序article 3 priority of contract document
构成本合同的文件可视为是能互相说明的,如果合同文件存在歧义或不一致,则根据如下优先次序来判断:
the documents consisting of this contract may be deemed as demonstrating mutually; if there is any ambiguity or discordance in the contract document, the following priority shall be followed to judgment,
3.1合同书 3.1 the contract;
3.2中标函(文件) 3.2 letter of acceptance (document);
3.3发包人要求及委托书 3.3 requirements of the employer and letter of authority;
3.4投标书 3.4 the tender
第四条 本合同项目的名称、规模、阶段、投资及设计内容(根据行业特点填写)
article 4 name, scale, phase, investment and design content for the contract items (fill in based on industry characteristics)
10kv星摩尔购物广场1#变电所新建工程
10kv star mall plaza 1 # substation new construction
变电所电气及10kv进线
electric and 10kv inlet wire of the substation
变电所设在地下,内设6台1600kva变压器及2台1250kva变压器。
the substation is underground, with six 1,600kva transformers and two 1,250kva transformers inside.
10kv电源分别由劝工变、历工变电所各新出电缆新路径电缆敷设至用户
变电所。
the 10kv power line is laid along the new cable roads of quangong substation and ligong substation respectively, toward the customer substation with cables.
第五条 发包人向设计人提交的有关资料、文件及时间
article 5 relevant materials, documents and time submitted to the designer
本工程供电方案 1份 20xx-2-25
power supply scheme of this project 1 25 february, 20xx
用电负荷资料 1份 20xx-2-25
by the employer
electricity load data 1 25 february, 20xx
第六条 设计人向发包人交付的设计文件、份数、地点及时间
article 6 documents, number of copies, location and time submitted to the employer by the designer
设计图纸 8份 20xx-04-15
design drawing 8 copies 15 april, 20xx
概算书 6份 20xx-04-15
book of estimates 6 copies 15 april, 20xx
注:待发包人结清全部设计费后,由设计人将设计文件交付沈阳供电公司客户工程部
note: after the party issuing contract settles up the total design fee, the above design documents will be submitted to the project division of shenyang power supply company by the designer.
第七条费用article 7 expenditure
7.1双方商定,本合同的设计费为设计费按设计价格(20xx)10号文计取 万元。收费依据和计算方法按国家和地方有关规定执行,国家和地方没有规定的,由双方商定。
7.1 it is agreed between both parties that the design fee under this contract is calculated and charged according to the document no.10 (20xx) design prices. the charging basis and method are in accordance with relevant national and local provisions, and will be determined by both parties through negotiation, if there is no relevant national or local provision.
7.2 如果上述费用为估算设计费,则双方在初步设计审批后,按批准的初步设计概算核算设计费。工程建设期间如遇概算调整,则设计费也应做相应调整。
7.2 if the above expense is estimated design fee, both parties shall check the design fee as per the approved budgetary estimate of the preliminary design, after the examination and approval of preliminary design. during the construction of this project, if there is any adjustment in budgetary estimate, the design fee will also be adjusted correspondingly.
第八条支付方式article 8 form of payment
8.1本合同生效后三天内,发包人支付设计费总额,计 16 万元作为定金(合同结算时,定金抵作设计费)。
8.1 the party issuing contract shall pay the total design fee, within three days after the execution of this contract, that is, 160000 rmb as a deposit (the deposit will be seen as a part of design fee, at the time of contract settlement).
8.2设计人提交 全部 设计文件之前,发包人结清设计费,不留尾款。
8.2 before the designer submits all design documents. the design charge is all squared by the employer, and no final payment left.
8.3双方委托银行代付代收有关费用。
8.3 both parties commission bank to pay and collect related fees.
第九条双方责任article 9 responsibility of two parties
9.1 发包人责任9.1 responsibility of the employer
9.1.1发包人按本合同第五条规定的内容,在规定的时间内向设计人提交基础资料及文件,并对其完整性、正确性及时限负责。发包人不得要求设计人违反国家有关标准进行设计。
发包人提交上述资料及文件超过规定期限15天以内,设计人按本合同第六条规定的交付设计文件时间顺延;发包人交付上述资料及文件超过规定期限15天以上时,设计人有权重新确定提交设计文件的时间。
9.1.1 the employer shall deliver basic materials and documents to the designer within the specified time in accordance requirements stipulated in article 5, and shall be responsible for their completeness, correctness and time limit. the employer shall not request the designer to design by violating the concerned national standards.
if it exceeds the prescribed time limit within fifteen (15) days when the employer delivers above materials and documents, the designer can postpone accordingly the time of delivering the design documents in accordance with article 6 in the contract; if it exceeds the prescribed time limit over fifteen (15) days when the employer delivers above materials and documents, the designer is entitled to decide again the time of delivery of design documents.
9.1.2发包人变更委托设计项目、规模、条件或因提交的资料错误,或所提交资料作较大修改,以致造成设计人设计返工时,双方除另行协商签订补充协议(或另订合同)、重新明确有关条款外,发包人应按设计人所耗工作量向设计人支付返工费。
9.1.2 when the employer alters entrusted design items, scale and conditions, or delivers the wrong materials, or delivers mostly revised materials so that the designer rework for the design, the employer shall pay for rework cost for the designer based on the amount of the work performed by the designer except the supplemental agreement (or contract ) signed separately, and the relevant articles specified again by both parties through the consultation.
prior to signing the contract, if the employer has satisfied to design work which is done by the designer, the employer shall pay the corresponding design charge.
在未签订合同前发包人已同意,设计人为发包人所做的各项设计工作,发包人应支付相应设计费。
9.1.3在合同履行期间,发包人要求终止或解除合同,设计人未开始设计工作的,不退还发包人已付的定金;已开始设计工作的,发包人应根据设计人已进行的实际工作量,不足一半时,按该阶段设计费的一半支付;超过一半时,按该阶段设计费的全部支付。
9.1.3 during implementation of the contract, when the employer requests to terminate and cancel the contract, the down payment paid by the employer shall not be returned if the designer doesnsquo;t begin the design work; if the designer starts the design, the employer shall pay half of design charge in the phase if it is less than half of the actual amount of work performed by the designer; if it exceeds the half, the full design charge in the phase shall be paid in all.
9.1.4发包人必须按合同规定支付定金,收到定金作为设计人设计开工的标志。未收到定金,设计人有权推迟设计工作的开工时间,且交付文件的时间顺延。
9.1.4 the employer shall pay the down payment in accordance with stipulations of the contract. reception of the down payment is the mark of commencement of design work for the designer. if the down payment is not received, the designer is entitled to put off the time of commencement of design work, and postpone accordingly the time of delivery of documents.
9.1.5发包人应按本合同规定的金额和日期向设计人支付设计费,每逾期支付一天,应承担应支付金额千分之二的逾期违约金,且设计人提交设计文件的时间顺延。逾期超过30天以上时,设计人有权暂停履行下阶段工作,并书面通知发包人.发包人的上级或设计审批部门对设计文件不审批或本合同项目停缓建,发包人均应支付应付的设计费。
9.1.5 the employer should pay charges for design to the designer at the amount and date provided in this contract. for each day of overdue payment, 2‰ of the overdue payment shall be paid as damages for overdue payment and the time for delivery by the designer shall be extended accordingly. where the delay of payment has exceeded 30 days, the designer shall have the right to suspend the performance of the work at the next stage and give written notice to the employer. in case the higher authority or competent department of design approval would not approve the design documents or the engineering construction of this contract is suspended or stopped, the employer should pay the payable charges for design.
9.1.6发包人要求设计人比合同规定时间提前交付设计文件时,须征得设计人同意,不得严重背离合理设计周期,且发包人应支付赶工费。
9.1.6 the employer requests the designer should deliver the design documents ahead of the time specified by the contract, it shall need the approval of the designer, and shall not deviate gravely from the rational design period, and the employer shall pay for the crashing charge.
9.1.7发包人应为设计人派驻现场的工作人员提供工作、生活及交通等方面的便利条件及必要的劳动保护装备。
9.1.7 the employer should offer conveniences in aspects of working, living and traffic and necessary labor-protection equipments.
9.1.8设计文件中选用的国家标准图、部标准图及地方标准图由发包人负责解决。
9.1.8 the employer shall be responsible for the national standard drawing, ministerial standard drawing and local standard drawings.
9.1.9承担本项目外国专家来设计人办公室工作的接待费(包括传真、电话、复印、办公等费用)。
9.1.9 the employer shall bear the expenses for receiving foreign expert in charge of the engineering to the designer's office (including expenses on fax, telephone, copy and office affairs).
9.2设计人责任9.2 responsibilities of the designer
9.2.1设计人应按国家规定和合同约定的技术规范、标准进行设计,按本合同第六条规定的内容、时间及份数向发包人交付设计文件(出现9.11、9.12、9.14、9.15、规定有关交付设计文件顺延的情况除外).并对提交的设计文件的质量负责。
9.2.1 the designer shall perform the design in accordance with provisions of the state and the technical codes and standards stipulated in the contract, deliver the design documents in accordance with contents, time and number of copies to the employer specified in article 6 (exclusion of the case where the design documents shall be prolonged accordingly stipulated in article 9.11, 9.12, 9.14 and 9.15), and be responsible for quality of the delivered design documents.
9.2.2设计合理使用年限为25年。
9.2.2 the design life of the engineering construction shall be 25 years.
9.2.3负责对外商的设计资料进行审查,负责该合同项目的设计联络工作。
9.2.3 responsible for examining for design materials of foreign businessman, and responsible for design liaison of the contract project.
9.2.4设计人对设计文件出现的遗漏或错误负责修改或补充。由于设计人设计错误造成工程质量事故损失,设计人除负责采取补救措施外,应免收受损失部分的设计费,并根据损失程度向发包人支付赔偿金,赔偿金数额由双方商定为实际损失的 \%。
9.2.4 the designer shall be responsible for revision or supplement to the mistakes or omission of the design documents. the designer shall be free of the design charge of loss part besides remedial measures taken for casualty loss of construction quality caused by the designer due to the wrong design, and shall pay compensation money for the employer based on degree of loss. amount of compensation which is decided by two parties through consultation is \% of actual loss.
9.2.5由于设计人原因,延误了设计文件交付时间,每延误一天,应减收该项目应收设计费的千分之二。
9.2.5 if the delivery of design documents is delayed for the designer's reason, each day overdue will result in the reduction of 2‰ of the design charges for the project.
9.2.6合同生效后,设计人要求终止或解除合同,设计人应双倍返还发包人已支付的定金。
9.2.6 after the contract enters into force, the designer may require termination or cancellation of the contract and the designer should return the down payment in double.
9.2.7设计人交付设计文件后,按规定参加有关上级的设计审查,并根据审查结论负责不超出原定范围的内容做必要调整补充。设计人按合同规定时限交付设计文件一年内项目开始施工,负责向发包人及施工单位进行设计交底、处理有关设计问题和参加竣工验收。在一年内项目尚未开始施工,设计人仍负责上述工作,可按所需工作量向发包人适当收取咨询服务费,收费额由双方商定。
9.2.7 upon delivery of the design documents, the designer shall participate in the inspection on the design by the relevant higher authority as provide and shall be responsible for necessary adjustment and supplements to the content within the original scope of the design according to the inspection conclusion. the designer shall start the construction within one year upon delivery of the design documents within the specified time limit and shall be responsible for the technological disclosure to the employer and construction unit, handling with relevant matters on design and participation in the acceptance upon completion of the engineering construction. in case the engineering construction has not started within one year, the designer shall still be responsible for the above work and may collect reasonable service charge for consultancy from the employer according to the needed workload. the amount of the service charge shall be discussed and determined by the parties.
第十条保密article 10 confidentiality
双方均应保护对方的知识产权,未经对方同意,任何一方均不得对对方的资料及文件擅自修改、复制或向第三人转让或用于本合同项目外的项目。如发生以上情况,泄密方承担一切由此引起的后果并承担赔偿责任。
both parties shall protect each othersquo;s intellectual property rights. without prior consent, neither party shall revise, copy or transfer to a third party or use for the project other than the project of this contract any materials and documents of the other party. under such circumstances, the disclosing party shall be responsible for all the any consequence it resulted and shall bear the relevant compensation.
第十一条仲裁article 11: arbitration
本建设工程设计合同发生争议,发包人与设计人应及时协商解决。也可由当地建设行政主管部门调解,调解不成时,双方当事人同意由沈阳仲裁委员会仲裁。双方当事人未在合同中约定仲裁机构,当事人又未达成仲裁书面协议的,可向人民法院起诉。
if any dispute arises in connection with this engineering service contract, it shall be settled by friendly consultation of the parties, or be submitted to the competent local construction administration department for mediation. where the dispute can not be settled by mediation, it shall be submitted to the shenyang arbitration committee for settlement. where the parties have not agreed on the arbitration organization in the contract nor conclude arbitration agreement in written form, the dispute will be brought to the peoplesquo;s court.
第十二条合同生效及其他article 12: contract effective and miscellaneous
12.1发包人要求设计人派专人长期驻施工现场进行配合与解决有关问题时,双方应另行签订技术咨询服务合同。
12.1 as per the request of the employer for dispatch of personnel to stay on the construction site so as to coordinate and solve relevant issues, the individual technical consultant service contract shall be signed by both parties.
12.2设计人为本合同项目的服务至施工安装结束为止。
12.2 service provided by the designer for the project in this contract will be concluded until the completion of construction and installation.
12.3本工程项目中,设计人不得指定建筑材料、设备的生产厂或供货商。发包人需要设计人配合建筑材料、设备的加工订货时,所需费用由发包人承担。
12.3 in the projects of the contract, designer shall not appoint manufacturers or designers of construction materials and equipments. where there is a necessity that designer shall cooperate with employer in ordering the process of construction materials and equipments, the relevant charge shall be paid by employer.
12.4发包人委托设计人配合引进项目的设计任务,从询价、对外谈判、国内外技术考察直至建成投产的各个阶段,应吸收承担有关设计任务的设计人员参加。出国费用,除制装费外,其他费用由发包人支付。
12.4 the employer entrusted the designer to cooperate with the engineering work of imported project and design personnel undertaking relevant design assignment shall be included in all stages from enquiry, business negotiation, domestic and overseas technical inspection until the production period. the charge for overseas business trip and other relevant charge will be paid by employer except the charge for purchasing dress.
12.5发包人委托设计人承担本合同内容以外的工作服务,另行签订协议并支付费用。
12.5 additional agreement for any other service, which employer entrusts designer to provide, however, out of the scope of the contract, shall be signed and the payment shall be paid correspondingly.
12.6由于不可抗力因素致使合同无法履行时,双方应及时协商解决。
12.6 for any failure to perform any term or condition of this contract due to the force majeure, both parties shall, in good faith, attempt to settle amicably and by mutual agreement.
12.7本合同双方签字盖章即生效。一式贰份,发包人壹份,设计人壹份。
12.7 the contract is effective once after both parties stamped and signed. there are totally __two_ copies of the contract, employer retains __one_ copies, and designer retains __one__ copies.
12.8本合同生效后,按规定应到项目所在地省级建设行政主管部门规定的审查部门备案;双方认为必要时,到工商行政管理部门鉴证。双方履行完合同规定的义务后,本合同即行终止。
12.8 once this contract became effective, it should be registered in the auditing section stipulated by provincial administrative ministry of construction where the project locates. where is necessity mutually agreed by both parties, the contract shall be certified by local administration for industry and commerce. this contract is to be concluded once after both parties fulfilled their own responsibilities.
12.9双方认可的来往传真、电报、会议纪要等,均为合同的组成部分,与本合同具有同等法律效力。
12.9 any correspondence, include faxes, telegram, meeting minutes agreed by both parties, are components of the contract, which shall have the same validity with this contract.
12.10未尽事宜,经双方协商一致,签订补充协议,补充协议与本合同具有同等效力。
12.10 as for matters not covered in this agreement, supplementary agreement may be concluded by the parties separately and such supplementary agreement shall have the same legal validity with this contract.
发包人名称:name of the employer:设计人名称:name of the designer:
(盖章)(stamp) (盖章)(stamp)
法定代表人:(签字)legal representative: (signature) 法定代表人:(签字)legal representative: (signature)
委托代理人:(签字)authorized proxy: (signature) 委托代理人:(签字)authorized proxy: (signature)
项目经理:(签字)project manager: (signature) 项目经理:(签字) project manager: (signature)
住 所: address: 住 所:address:
邮政编码: postcode: 邮政编码: postcode:
电话: tel.: 电话:tel.:
传真: fax: 传真:fax:
开户银行: bank: 开户银行: bank:
银行帐号: bank account: 银行帐号:bank account:
建设行政主管部门备案: 鉴证意见:verification opinion:
record at the competent construction
administration department:
(盖章)(stamp) (盖章)(stamp)
备案号: 经办人:
record no.: agent:
备案日期: 年月日 鉴证日期:年月日
会计实习心得体会最新模板相关文章: